Loading...
HomeMy WebLinkAboutInamagua-WorkOrder 8862 35W West Service Drive N.E. NAA/ Date of Agreement: Blaine, MN 55449 April 2022 WINDOW NATION Sales: 866-446-2846 License#: FILL IN WHEN RECEI� —WINDOWS • SIDING • DOORS Service: 866-217-9582 PRODUCT SPECIFICATIONS Buyer's Information and Buyer Contact Information: Buyer Email Information: Description of Property: (612)462-5648 Primary Mobile finamagual8@hotmail.com Frank Inamagua Diana Inamagua 7361 Concerto Cury NE Fridley, MN 55432 Buyer(s) listed above hereby jointly and severally agrees to purchase the goods and/or services listed on the accompanying specification sheets, in accordance with the prices and terms described in the Custom Remodeling and Improvement and the Product Specifications (collectively, this "Agreement"). Windows-Belle Vue inclusions:Beveled exterior frame with drip-cap,Fusion welded frame and sashes,Limit lock on double hung windows, Multi-Layer weatherstripping , Defense-Tek Cam-action lock, Special formula uPVC, Constant force balance system on double hung window,Integral lift rail, Super Spacer, CoreFX reinforced meeting rail, Forecaster sloped sill, Gatekeeper sash-to-sill interlock, exterior custom capping, installation by factory certified crew,clean up and haul away of all job related debris. DO NOT SIGN THIS CONTRACT IF THERE ARE ANY BLANK SPACES. It is agreed and understood by and between parties that the Product Specifications, along with the Custom Remodeling and Improvement Agreement, constitutes the entire understanding between the parties, and replaces any and all prior negotiations, representations, or agreements, either written or oral. The Product Specifications may not be changed, modified, or varied in any way (with exception that installation materials may be substituted with similar products when inventory shortages exist)unless such changes are in writing and signed by both Buyer(s) and Window Nation, LLC. Buyer(s)hereby acknowledge that Buyer(s)has read the Product Specifications. I have read and received each page of this 2 page Product Specification. Wi ow ation Buyer(s) Signature of Exterior Design Consultant Signature Joseph Zytkovicz-License#On File YOU, THE CONSUMER,MAY CANCEL THIS TRANSACTION AT ANY TIME PRIOR TO MIDNIGHT OF THE THIRD BUSINESS DAY AFTER THE DATE OF THIS TRANSACTION. SEE THE ATTACHED NOTICE OF CANCELLATION FORM FOR AN EXPLANATION OF THIS RIGHT. April 20, 2022 www.windownation.com Page 1 of 2 8862 35W West Service Drive N.E. NAA/ Date of Agreement: Blaine, MN 55449 April 2022 WINDOW NATION Sales: 866-446-2846 License#: FILL IN WHEN RECEI� —WINDOWS • SIDING • DOORS Service: 866-217-9582 PRODUCT SPECIFICATIONS Buyer's Information and Buyer Contact Information: Buyer Email Information: Description of Property: (612)462-5648 Primary Mobile finamagual8@hotmail.com Frank Inamagua Diana Inamagua 7361 Concerto Cury NE Fridley, MN 55432 Work Order Details: Model:Belle Vue W:47"H:39" Location:Level 2,future baby roo - j Quantity: 1 • Style:2 Part Slider • Grids:None • Glass:Extreme 2 Pane/Low-E&Argon • Screen:Half Screen • Color:Interior White/Exterior White Model: Belle Vue W:47" H:39" Location:Level 2,Bedroom(maste - 2 Quantity: I • Style:2 Part Slider • Grids:None • Glass:Extreme 2 Pane/Low-E&Argon • Screen:Half Screen • Color:Interior White/Exterior White Additional Items 2-EPA Lead Containment Install-Window(Per Opening) Installation Details: Window Removal Type:Wood Additional products needed in the future:No Exterior Trim: G8 Exterior Trim Color:American terra Customer agrees to allow Window Nation to post a yard Sealant: OSI Quad Max sign until 30 days after install: Yes Insulation Around Window: OSI Quad Foam Year house was built: 1968 Clean Up and Haul Away: Yes EPA Lead Containment Required: Yes EPA Lead Testing Required: Yes HOA Approval Required:No April 20, 2022 www.windownation.com Page 2 of 2 8862 35W West Service Drive N.E. NAA/ Date of Agreement: Blaine, MN 55449 April 2022 WINDOW NATION Sales: 866-446-2846 License#: FILL IN WHEN RECEI� —WINDOWS • SIDING • DOORS Service: 866-217-9582 CUSTOM REMODELING AND IMPROVEMENT AGREEMENT Buyer's Information and Buyer Contact Information: Buyer Email Information: Description of Property: (612)462-5648 Primary Mobile finamagual8@hotmail.com Frank Inamagua Diana Inamagua 7361 Concerto Cury NE Fridley, MN 55432 Buyer(s)listed above hereby jointly and severally agrees to purchase the goods and/or services of Window Nation,LLC. ("Contractor")in accordance with the prices and terms described in this 6 page document and the Product Specifications,which are incorporated as part of the Agreement(collectively,this "Agreement"). This Agreement represents a cash sale of goods and services. Buyer(s)agrees to pay the cost of the goods and services purchased as described herein,regardless of timing or approval of any financing Buyer(s)may seek for their purchase. Sale Total $2,381.00 Setup&Disposal Fee $0.00 Estimate Project Start: 14 to 16 weeks Permit Fee $0.00 Estimate Project Finish: 1 to 3 days after start Total Sale Price $2,381.00 Sales Tax(0%) $0.00 Total Amount Due $2,381.00 Buyer(s)acknowledge that definite start and completion Down payment-Charge $786.00 dates are NOT of the essence. Delays beyond Contractor's Balance Due $1,595.00 control not included in calculating timeframes. See COD(Payable at time of install) $1,595.00 Section 5 of the Terms and Conditions. Amount Financed $0.00 This Agreement constitutes the entire agreement and understanding between the parties,and this Agreement replaces any and all prior negotiations,representations,or agreements,either written or oral. No amendment,modification or waiver of this Agreement shall be valid or effective unless in writing and signed by both parties. Buyer(s)hereby acknowledge that Buyer(s) 1)has read the entire Agreement and has received a completed, signed,and dated copy of this Agreement,including the two accompanying Notice of Cancellation forms,on the date first written above and 2)was orally informed of his/her right to cancel this transaction. Buyer(s)also agrees and understands that if Buyer(s)finance the work with a third-parry,the terms of that financing will be contained on separate documents,including any finance charge. Price includes all discounts and promotions. I have read and received each page of this 5 page Agreement. Wi ow ation Buyer(s) Signature of Exterior Design Consultant Signature Joseph Zytkovicz-License#On File YOU, THE CONSUMER,MAY CANCEL THIS TRANSACTION AT ANY TIME PRIOR TO MIDNIGHT OF THE THIRD BUSINESS DAY AFTER THE DATE OF THIS TRANSACTION. SEE THE ATTACHED NOTICE OF CANCELLATION FORM FOR AN EXPLANATION OF THIS RIGHT. April 20, 2022 www.windownation.com Page 1 of 5 8862 35W West Service Drive N.E. NAA/ Date of Agreement: Blaine, MN 55449 April 2022 WINDOW NATION Sales: 866-446-2846 License#: FILL IN WHEN RECEIE-WINDOWS • SIDING • DOORS Service: 866-217-9582 CUSTOM REMODELING AND IMPROVEMENT AGREEMENT Buyer's Information and Buyer Contact Information: Buyer Email Information: Description of Property: (612) 462-5648 Primary Mobile finamagual8@hotmail.com Frank Inamagua Diana Inamagua 7361 Concerto Cury NE Fridley, MN 55432 TERMS AND CONDITIONS 1.Description of the Work to be Performed:Window Nation,LLC("Contractor")agrees to do the described work noted on the front of the document(the"work")at the job location(the"Property")for the customer("Owner")identified in this contract(the"Agreement"). 2.Electronic Contract: A contract is an agreement reached between two or more parties,which is legally enforceable in accordance with specific requirements. Online and/or Electronic Contracts are as valid and enforceable as a paper contract. For purposes of the Window Nation Contract,an online signature is intended to be as binding and as enforceable as a signature on a paper version of the contract. Owner agrees that Contractor's electric-contracts,which are signed with an online signature,is fully enforceable and subject to the same requirements and restrictions as a written contract. 3.Payment of Funds and Deposit: Owner agrees to pay Contractor a deposit as noted on front of this Agreement at the time of the execution of this Agreement and to pay the balance due,as reflected in the final invoice prepared by Contractor("the invoice"),upon completion of installation. Presentation of the invoice is notice to Owner that Contractor considers the Work complete. All payments made pursuant to this Agreement shall only be made to Contractor. 4.Late Payment/Finance Charge:Any funds owed greater than thirty(30)days beyond the Completion Date are subject to a service charge of one and one-half percent(1.5%)per month interest on the unpaid balance. The definition of Completion Date is the date in which the original install was performed. The need to service the job after the date of the original install does not affect the Completion Date. 5.Customer No Show at Measure or Installation: A customer no show occurs when Owner is not at home at a prescheduled final measure appointment or product installation,and does not provide adequate notice to Contractor of intent to reschedule measure or installation. Notice will only be deemed adequate if Owner contacts Contractor a minimum of 24 hours prior to scheduled appointment. Same day notification is not adequate notice. If adequate notice is not provided and Owner is not home at the time of the prescheduled final measure appointment,Owner agrees to pay Contractor a$75 missed measure fee,which will be due at the completion of the job, and payment of which will be a prerequisite to activating Owner's warranty. If adequate notice is not provided and Owner is not home at the time of the prescheduled installation appointment,Owner agrees to pay Contractor a$350 missed installation fee,which will be due at the completion of the job,and payment of which will be a prerequisite to activating Owner's warranty. If these fees become due,they must be paid in by cash,check,money order or credit card and cannot be added to any financed amount. These fees also do not impact the validity of the original contract,which remains fully in effect. 6.Work Schedule: Contractor agrees to perform the Work in good and workmanlike manner with reasonable dispatch in accordance with the specifications listed above. Contractor is responsible for establishing scheduling and sequencing of the work to be performed. Contractor shall endeavor to actually commence Work(the"Actual Start Date")on the Estimated Start Date(as hereafter defined) established at the time of contract acceptance by the Contractor.Contractor will strive to have the Actual Start Date commence no later than sixty(60)days from the Estimated Start Date.The Estimated Start Date or the Actual Start Date may be altered by Contractor for reasonable delay. Reasonable delays include,but are not limited to,non-delivery,discontinuance,default in shipment by a supplier in whole or in part,loss in transit,strikes,lockouts,weather or other causes beyond Contractor's control. Owner must schedule an installation date within fourteen(14)days after the windows arrive in the warehouse for no more than thirty(30)days after arrival. 7.Materials:All materials shall remain the property and title of Contractor until fully paid by Owner. All surplus materials shall remain the property of Contractor unless,at Contractor's option,are turned over to Owner upon the completion of the work. Contractor is not responsible for replacement of any lumber, sheathing,trim or rotted wood,or replacement parts in excess of the agreed amount unless specified in this Agreement. 8.Changes in Contract: Owner hereby expressly authorizes any of the joint signatories,if there are any,or any of his agents, servants, employees,attorney-in fact,or personal representatives to execute and deliver to Contractor any additional changes to this Agreement by a change order(Change Order). Such Change Order shall be binding and conclusive on said Owner. Owner hereby acknowledges that any Change Orders requested by Owner and approved by Contractor pursuant to this section of this Agreement, shall be paid per the terms of Section 3 of this Agreement. Any changes made to this Agreement as required by regulatory agencies will be at additional cost to Owner,unless such changes or additions are cited in this Agreement. Furthermore,by signing this Agreement,Owner acknowledges that no change has been made to this Agreement by any salesperson or other agent on behalf of Owner. Such changes to this Agreement may only occur if a Change Order exists that has been approved by Contractor. Electronic Change Orders with an electronic signature are as enforceable as a written change order with a written signature. Verbal requests for changes do not adequately result in a Contractor approved Change Order. April 20, 2022 www.windownation.com Page 2 of 5 8862 35W West Service Drive N.E. NAA/ Date of Agreement: Blaine, MN 55449 April 2022 WINDOW NATION Sales: 866-446-2846 License#: FILL IN WHEN RECEI� —WINDOWS • SIDING • DOORS Service: 866-217-9582 CUSTOM REMODELING AND IMPROVEMENT AGREEMENT Buyer's Information and Buyer Contact Information: Buyer Email Information: Description of Property: (612)462-5648 Primary Mobile finamagual8@hotmail.com Frank Inamagua Diana Inamagua 7361 Concerto Cury NE Fridley, MN 55432 TERMS AND CONDITIONS (cont.) 9.Owner's Responsibilities: a.Owner warrants to Contractor that he is the legal owner of the Property. Owner agrees to provide to Contractor,at no charge,electric power and water for construction purposes. Owner acknowledges that the removal of permanently attached building materials often disturbs and vibrates the existing property. The debris generated from this Work and other related procedures to this Work may cause inconvenience or discomfort,which is normal construction conditions,and not Contractor negligence. These normal construction conditions may include,but are not limited to minor interior cracks,dusting or flaking of wall paint,debris falling in an attic,potential disturbance and/or damage to shrubbery and lawns,and divots in driveways.As a precaution, Owner is responsible for removing from walls or ceilings,items such as,but not limited to,chandeliers,paintings,plates and other breakable items. Furthermore,Owner shall lock away or secure other items of value in or on the Property. Owner is responsible for the fees and costs associated and required for any local building permit,which Contractor will obtain as necessary. Owner or authorized representative shall make themselves available during construction for clarification of specifications;approval of additional Work,and to provide adequate access to the Property as may be required.Owner or authorized representative of Owner must be present at the completion of Work to review the completed Work and address final payment funds.b.On occasion Contractor will discover circumstances after the original contract is signed that will increase the cost of the materials or labor on the job, such as damaged or rotten wood that could not be determined until the time of measure or installation. If it is determined that such circumstances exist, Owner shall either repair any unforeseen circumstances within seven(7)days or direct Contractor to perform the necessary repairs at a mutually agreed upon additional cost,which will be documented through a Change Order, signed by Owner,and due upon the completion of the project.c.Owner shall remove all drapes,blinds and window treatments of whatever nature,kind or size prior to Contractor performing any Work. Contractor shall not be responsible for the removal of,or damage to, such drapes,blinds or window treatments due to Owner's failure to comply with this provision. Contractor shall not be responsible for any window covering fit after the installation of windows. Owner shall remove any air conditioning units prior to Work. Contractor shall not be responsible for the removal or reinstallation of,or damage to,window air conditioning units or for proper fit of such unit into replacement window. Owner acknowledges that Contractor shall not be responsible for painting touching up and/or plastering existing walls and/or woodwork after installation of the windows provided for in this Agreement. Owner shall be responsible for having any existing security systems reactivated and/or rewired after installation of new windows and/or vinyl siding. Contractor shall not be responsible for any expenses incurred by Owner for such existing security systems and/or wiring.d.In the event Owner's homeowner's association approval is required,Contractor shall provide Owner with information regarding the details of the work to be done under this Agreement. It shall be the Owner's responsibility to promptly and diligently submit the information and obtain approval for the design of the Work to be done and to notify Contractor within ten(10)days of the approval/rejection of the request by Owner's homeowner's association.e.Owner shall move all existing furniture at least three feet away from windows being replaced prior to the installation date. Contractor shall not be responsible for moving furniture or damage to furniture due to failure of Owner to comply with this provision.f.Owner acknowledges that if this Agreement is for the purchase and installation of both replacement windows and vinyl siding,Owner shall pay the balance due and owing for the sale and installation of replacement windows at the completion of the installation of the replacement windows and shall pay the balance due and owing for the sale and installation of vinyl siding at the completion of installation of the vinyl siding.g.By signing this Agreement,Owner(s)hereby authorize Contractor and/or its designee(s)to make whatever inquiries it or they deem necessary in connection with this Agreement,including but not limited to the procurement of credit reports from consumer reporting agencies. Furthermore,Owner agrees that such information procured in relation to this Agreement,including this Agreement, shall remain Contractor's property regardless of the ultimate outcome of the Agreement.h.Owner represent and warrants that he, she or they have the present ability to pay in full the amount of money due Contractor under this contract. Allowing the custom windows to be measured,built and/or installed is an acknowledgement by Owner that they are able to pay Contractor at the completion of the project. In the event Contractor determines,in its sole and absolute discretion,that Owner may be unable to pay any amount when due, Contractor reserves the right to stop all work and remove all uninstalled supplies and/or goods and equipment from the Property until the entire unpaid balance of the Contract price has been either paid to Contractor or is placed in escrow depending on the rules and regulations of the governing body. Any expenses incurred as a result of this action are the sole responsibility of the Owner,including but not limited to escrow fees and reasonable attorney's fees charged to the Contractor. April 20, 2022 www.windownation.com Page 3 of 5 8862 35W West Service Drive N.E. NAA/ Date of Agreement: Blaine, MN 55449 April 2022 WINDOW NATION Sales: 866-446-2846 License#: FILL IN WHEN RECEI� —WINDOWS • SIDING • DOORS Service: 866-217-9582 CUSTOM REMODELING AND IMPROVEMENT AGREEMENT Buyer's Information and Buyer Contact Information: Buyer Email Information: Description of Property: (612)462-5648 Primary Mobile finamagual8@hotmail.com Frank Inamagua Diana Inamagua 7361 Concerto Cury NE Fridley, MN 55432 TERMS AND CONDITIONS (cont.) i. Should Owner fail to adhere to the responsibilities presented in Section 9,which in turn results in the inability to proceed with the scheduled installation,Owner agrees to pay Contractor a$350 missed installation fee,which will be due at the completion of the job,and payment of which will be a prerequisite to activating Owner's warranty. If this fee becomes due,it must be paid by cash,check money order or credit card and cannot be rolled into any financed amount. This fee also does not impact the validity of the original contract, which remains fully in effect. 10.Cancellation of Agreement: Should Owner cancel this Agreement for any reason by providing the Notice of Cancellation(as otherwise defined herein)prior to the end of the rescission date of this Agreement,Contractor shall return to Owner all payments made under this Agreement within ten(10)days of receipt of the Notice of Cancellation of this Agreement which is incorporated herein and made a part hereof. Should Owner cancel this Agreement for any reason after the end of the rescission date of this Agreement,Owner agrees to pay Contractor the following sums as liquidated damages,which the Parties hereto agree is a fair and reasonable amount incident to the costs and expenses incurred by Contractor in connection with this Agreement. ff Owner cancels this Agreement after the end of the rescission date but before the windows are ordered,Owner agrees to pay Contractor thirty percent(30%)of this Agreement's Sales Total forthwith;or should Owner cancel this Agreement after product has been ordered,Owner agrees to pay Contractor sixty percent(60%)of this Agreement's Sales Total plus a proportionate share of all Work performed or product ordered. Contract is not subject to any cancellation period if signed in showroom. Buyer's and Co-Buyer's Right to Cancel are not affected by the use of an electronic contract,which is enforced with an electronic signature. 11.Default: Owner shall be in default of this Agreement at any time he does not tender payments as listed in section 3 of the Terms and Conditions of this Agreement. Upon Owner's default,Contractor may immediately discontinue Work and the entire balance due shall be immediately due and payable. Waiver or indulgence of any default shall not operate as a waiver of any default on future occasions. 12.Attorneys'Fees:In the event that this bill is referred for collection the unpaid balance shall be subject to attorneys'fees of thirty-three and one third percent(33 1/3%)of total Contract amount.Additionally any unpaid balance is subject to an interest rate of eighteen percent(18%)APR,or the maximum amount allowed by law 13.Contractor Not Liable-Owner acknowledges that at no time shall Contractor's liability exceed the total amount charged for the Work performed under this Agreement.Contractor shall not be liable for any defects,which are characteristic to the particular material such as cracks to walls or ceilings of existing structures.Contractor assumes no liability for damages including but not limited to existing landscaping trees or shrubs. 14.Contractor Warranty:Except as otherwise provided herein,in order for any warranty to be effective against Contractor or any other parry,Owner must(a)have paid all sums owed to Contractor under this Agreement, (b)provide by immediate,but not later than ten(10) days,written notice by certified mail to Contractor upon discovering any defect or failure of the Work performed and(c)not have in anyway altered or repaired any of the Work performed by Contractor. Long-term warranties provided by the manufacturer will be assigned,to the extent assignable,to Owner upon payment in full for Work performed by Contractor. Any warranties provided for in this Agreement shall begin to run on the Completion Date. Contractor's warranty shall be limited to warranty on labor. 15.Mold:Moisture that has entered into the Property may result in the existence,development or growth of mold,mildew,fungi or other similar microbial conditions(Collectively"Mold"). Contractor has no experience,expertise,or information regarding Mold or the detection of Mold. Contractor and Owner hereby agree that Contractor is not responsible for any property damage,personal injury,loss of income,emotional distress,death,loss of use,loss of value,and adverse health effects resulting from the existence,development or growth of Mold either prior to,during,or after performance of the Work.Owner agrees to release and indemnify Contractor from all claims,penalties,actions,liabilities,costs,expenses,and damages Owner,Owner's family and any and all of Owner's third parry invitees that may be effected by the presence of Mold in Owner's home. 16.Use of Photos: Owner gives Contractor consent to take photographic pictures,videos or other likenesses,before,during and after the completion of the Work. Owner consents to allow Contractor to use photos,videos and other likenesses for promotional purposes, including but not limited to Contractor's website. 17.Outside Financing: ff the Work is financed through an outside lending agency,Owner agrees to execute and deliver necessary finance papers,mortgage,or other forms required by the lending agency in advance of commencement of the Work. Upon notice of the Substantial Completion of the Work,Owner will execute a completion slip if required. April 20, 2022 www.windownation.com Page 4 of 5 8862 35W West Service Drive N.E. NAA/ Date of Agreement: Blaine, MN 55449 April 20, 2022 WINDOW NATION Sales: 866-446-2846 License#: FILL IN WHEN RECEI� —WINDOWS • SIDING • DOORS Service: 866-217-9582 CUSTOM REMODELING AND IMPROVEMENT AGREEMENT Buyer's Information and Buyer Contact Information: Buyer Email Information: Description of Property: (612)462-5648 Primary Mobile finamagual8@hotmail.com Frank Inamagua Diana Inamagua 7361 Concerto Cury NE Fridley, MN 55432 TERMS AND CONDITIONS (cont.) 18.Binding Contract: This agreement is subject to review by the authorized members of management for Contractor.This agreement, until approved by Contractor,is subject to change or revocation by Contractor.Upon approval by Contractor,this agreement shall constitute a binding agreement between the Contractor and Owner.In the event, such approval is not granted within thirty(30)days of the date of this Agreement,the Deposit paid by the Owner will be refunded without interest and this Agreement shall be deemed not approved and neither the Contractor nor the Owner shall be liable to each other for costs or damages.Notwithstanding anything contained herein to the contrary,Contractor reserves the right to reject or cancel all or part of this Agreement due to unacceptable payment performance or credit rating of the Owner or any pricing error by sales consultant. 19.No Waiver:The Contractor may accept late payments or partial payment,checks,bank drafts,or money orders marked"Paid in Full" without waiving any of its rights related to this Agreement. 20.Entire Agreement:This Agreement constitutes the entire agreement between the Parties. Contractor is not liable for nor bound in any manner by any statements,representations,warranties,collateral or otherwise,or promises made by any person representing or proposing to represent Contractor unless such statements,representations,or promises are set forth in this Agreement. Any modification of this Agreement must be in writing and signed,electronic or handwritten,by the Parties. Electronic signatures are as enforceable as handwritten signatures. 21. Severability:If any provisions,paragraphs,or subparagraph of this Agreement is adjudged by any court to be void or unenforceable in whole or in part,this adjudication shall not affect the validity of the remainder of this Agreement. Each provision of this Agreement is severable from every other provision,and constitutes a separate and distinct covenant. 22.Choice of Law;Jurisdiction:This Agreement shall be construed in accordance with the laws of the State of Maryland. Any legal action to be instituted hereunder shall be filed in the appropriate Court in the State of Maryland,and each party hereby consents to the jurisdiction of the Courts of the State of Maryland.Notwithstanding the foregoing,in the event of a breach of this Agreement that necessitates Contractor to seek legal action,nothing in these terms and conditions shall limit Contractor's right to bring a legal suit, action,or proceedings against Owner in any other State Court or other forum of proper jurisdiction. 23.Interpretation:No provision of this Agreement is to be interpreted for or against any party because that party or such party's legal representative drafted such provision. 24.Insurance: Seller will maintain any and all mandated insurance coverage,included but not limited to property damage insurance. 25.Use of Contact Information: Owner consents and authorizes Contractor's use of Owner's contact information(address,phone numbers,email)for purposes of future communications by Contractor to Owner about events,promotions,and offers being presented by Contractor.Owner may request removal from this list by submitting a written letter to the following address: 8110 Maple Lawn Blvd, Fulton,MD 20759 26.Window Nation,LLC conducts business under Federal Tax ID number 20-5084724. 27. Statutory Warranty.Pursuant to Minn. Stat. §327A.02, Subd.3(c),Contractor warrants to the Owner that,during the one-year period from and after the warranty date,the Work shall be free from defects caused by faulty workmanship or defective materials due to noncompliance with building standards. Owner agrees that a copy of the Agreement has been provided to them via email or printed means. Nevertheless, an additional copy will be available to Owner upon request. April 20, 2022 www.windownation.com Page 5 of 5 8862 35W West Service Drive N.E. NAA/ Date of Agreement: Blaine, MN 55449 April 20, 2022 WINDOW NATION Sales: 866-446-2846 License#: FILL IN WHEN RECEIE-WINDOWS • S f O, G • DOORS Service: 866-217-9582 Lead Form Buyer's Information and Buyer Contact Information: Buyer Email Information: Description of Property: (612) 462-5648 Primary Mobile finamagual8@hotmail.com Frank Inamagua Diana Inamagua 7361 Concerto Cury NE Fridley, MN 55432 • A, AtM C 1 &EPA .�yauotsua !i msa¢�sossasrs \EPA (� 8 y�yreaststiMa�YIMNt•gym. The Lead Safe Certified Guide to Renovate Right JN\QED ST4j�s www.epa.gov/getleadsafe r 1-800-424-LEAD (5323) W EPA-740-K-10-001 0 Q April 2010 Occupant Confirmation F2'A4 PRO-X Pamphlet Receipt 21 1 have received a copy of the lead hazard information pamphlet informing me of the potential risk of lead hazard exposure from the renovation activity to be performed in my dwelling unit. I received this pamphlet before the work began. Frank Inamagua April 20,2022 Signature Diana Inamagua April 20,2022 Signature April 20, 2022 www.windownation.com Page 1 of 1 8862 35W West Service Drive N.E. NAAZ Date of Agreement: Blaine, MN 55449 April 2022 WINDOW NATION Sales: 866-446-2846 License#: FILL IN WHEN RECEI�—WINDOWS • SIDING • DOORS Service: 866-217-9582 Contact Sheet - MIN Buyer's Information and Buyer Contact Information: Buyer Email Information: Description of Property: (612) 462-5648 Primary Mobile finamagual8@hotmail.com Frank Inamagua Diana Inamagua 7361 Concerto Cury NE Fridley, MN 55432 WINDOW • YOUR • Thank you for choosing Window Nation. We take great pride in making sure your entire experience exceeds your expectations,which is why we have a dedicated team to help you along the way should you ever need assistance. Reach Your Exterior Design Specialist For questions about your contract and/or to make changes, please see business card. Sales Manager: Bob Aruta Email: Baruta@windownation.com Phone: 612-357-3085 For questions about your Exterior Design Specialist(or if you cannot reach him/her) Production Manager: Paul Bierwerth Email: Pbierwerth@windownation.com Phone: 763- 330-1553 (For questions about your final measure,whether requested documents have been sent or receive,financing,etc.) Consumer Finance Manager: Katrina Dangerfield Email: kdangerfield@windownation.com Phone: 410-766-8488 x704 (For questions about your financing) Customer Service Department: 888-248-5764 (For all other inquiries(installation,scheduling,status,documents,service,warranty,etc.) To refer a friend and earn cash, visit www.windownation.com/refer-a-friend April 20, 2022 www.windownation.com Page 1 of 1 NOTICE OF CANCELLATION NOTICE OF CANCELLATION Date of Transaction: 04/20/2022 Date of Transaction: 04/20/2022 YOU MAY CANCEL THIS TRANSACTION WITHOUT YOU MAY CANCEL THIS TRANSACTION WITHOUT ANY PENALTY OR OBLIGATION, WITHIN 3 ANY PENALTY OR OBLIGATION, WITHIN 3 BUSINESS DAYS FROM THE ABOVE DATE. IF YOU BUSINESS DAYS FROM THE ABOVE DATE. IF YOU CANCEL, ANY PROPERTY TRADED IN, ANY CANCEL, ANY PROPERTY TRADED IN, ANY PAYMENTS MADE BY YOU, AND ANY NEGOTIABLE PAYMENTS MADE BY YOU, AND ANY NEGOTIABLE INSTRUMENT EXECUTED BY YOU UNDER THE INSTRUMENT EXECUTED BY YOU UNDER THE CONTRACT OR TRANSACTION WILL BE RETURNED CONTRACT OR TRANSACTION WILL BE RETURNED WITHIN 10 BUSINESS DAYS FOLLOWING RECEIPT WITHIN 10 BUSINESS DAYS FOLLOWING RECEIPT BY THE SELLER OF YOUR CANCELLATION NOTICE, BY THE SELLER OF YOUR CANCELLATION NOTICE, AND ANY SECURITY INTEREST ARISING OUT OF AND ANY SECURITY INTEREST ARISING OUT OF THE TRANSACTION WILL BE CANCELLED. IF YOU THE TRANSACTION WILL BE CANCELLED. IF YOU CANCEL, YOU MUST MAKE AVAILABLE TO THE CANCEL, YOU MUST MAKE AVAILABLE TO THE SELLER AT YOUR RESIDENCE IN SUBSTANTIALLY SELLER AT YOUR RESIDENCE IN SUBSTANTIALLY AS GOOD A CONDITION AS WHEN RECEIVED, ANY AS GOOD A CONDITION AS WHEN RECEIVED, ANY GOODS DELIVERED TO YOU UNDER THIS GOODS DELIVERED TO YOU UNDER THIS CONTRACT OR TRANSACTION, OR YOU MAY IF CONTRACT OR TRANSACTION, OR YOU MAY IF YOU WISH, COMPLY WITH THE INSTRUCTIONS OF YOU WISH, COMPLY WITH THE INSTRUCTIONS OF THE SELLER REGARDING THE RETURN SHIPMENT THE SELLER REGARDING THE RETURN SHIPMENT OF THE GOODS AT THE SELLER'S EXPENSE AND OF THE GOODS AT THE SELLER'S EXPENSE AND RISK. IF YOU MAKE THE GOOD AVAILABLE TO THE RISK. IF YOU MAKE THE GOOD AVAILABLE TO THE SELLER AND THE SELLER DOES NOT PICK THEM SELLER AND THE SELLER DOES NOT PICK THEM UP WITHIN 20 DAYS OF THE DATE OF YOUR UP WITHIN 20 DAYS OF THE DATE OF YOUR NOTICE OF CANCELLATION, YOU MAY RETAIN OR NOTICE OF CANCELLATION, YOU MAY RETAIN OR DISPOSE OF THE GOODS WITHOUT ANY FURTHER DISPOSE OF THE GOODS WITHOUT ANY FURTHER OBLIGATION. IF YOU FAIL TO MAKE THE GOODS OBLIGATION. IF YOU FAIL TO MAKE THE GOODS AVAILABLE TO THE SELLER, OR IF YOU AGREE TO AVAILABLE TO THE SELLER, OR IF YOU AGREE TO RETURN THE GOODS TO THE SELLER AND FAIL TO RETURN THE GOODS TO THE SELLER AND FAIL TO DO SO, THEN YOU REMAIN LIABLE FOR DO SO, THEN YOU REMAIN LIABLE FOR PERFORMANCE OF ALL OBLIGATIONS UNDER THE PERFORMANCE OF ALL OBLIGATIONS UNDER THE CONTRACT. TO CANCEL THIS TRANSACTION, CONTRACT. TO CANCEL THIS TRANSACTION, M R Y4�i�JI fKI I 7F11 �1�T D COPY OF M49R0RyDU4T9LXQetNRnNVX1naTED COPY OF THIS CANCELLATION NOTICE OR ANY OTHER THIS CANCELLATION NOTICE OR ANY OTHER WRITTEN NOTICE, OR SEND A TELEGRAM TO: 8862 WRITTEN NOTICE, OR SEND A TELEGRAM TO: 8862 35W West Service Drive N.E. Blaine, MN 55449 NOT 35W West Service Drive N.E. Blaine, MN 55449 NOT LATER THAN MIDNIGHT OF 4/23/2022. LATER THAN MIDNIGHT OF 4/23/2022. Consumer's Signature Date Consumer's Signature Date 8862 35W West Service Drive N.E. NAA/ Date of Agreement: Blaine, MN 55449 April 2022 WINDOW NATION Sales: 866-446-2846 License#: FILL IN WHEN RECEI� —WINDOWS • SIDING • DOORS Service: 866-217-9582 PRODUCT SPECIFICATIONS Buyer's Information and Buyer Contact Information: Buyer Email Information: Description of Property: (612)462-5648 Primary Mobile finamagual8@hotmail.com Frank Inamagua Diana Inamagua 7361 Concerto Cury NE Fridley, MN 55432 Order Summary: Belle Vue 2 2 Part Slider Grids:None Glass:Extreme 2 Pane/Low-E&Argon Screen:Half Screen Color:Interior White/Exterior White Total Order Summary of Units 2 Additional Items 2-EPA Lead Containment Install-Window(Per Opening) Installation Details: Window Removal Type:Wood Additional products needed in the future:No Exterior Trim: G8 Exterior Trim Color:American terra Customer agrees to allow Window Nation to post a yard Sealant: OSI Quad Max sign until 30 days after install: Yes Insulation Around Window: OSI Quad Foam Year house was built: 1968 Clean Up and Haul Away: Yes EPA Lead Containment Required: Yes EPA Lead Testing Required: Yes HOA Approval Required:No April 20, 2022 www.windownation.com Page 1 of I